CURE NOTICE, RESPONSE TO GOVERNMENT

Date

Mr. Contracting Officer

(Address)

Re: Contract No.

Dear Sir:

This is in response to your cure notice (or cure letter) dated .

(Note: Discuss in this letter the following:

Your entitlement to extra time, any requests that you have pending for compensable time, time due to adverse weather, time due to Government delays, and other causes.

If not your fault, do not admit fault for being behind schedule.

Note the positive actions that you are taking to correct known problems.

Request a meeting to discuss and explain the problems, whether your or the Government’s.

Assure the Government that it is your intent to complete the project in a timely manner, meeting all contract requirements.)